Thank you for visiting 360Techno. We are a company, creating products to enhance your website building experience. Please read this Terms & Conditions.
• All estimates/quotes are based on our understanding of your requirements and as per given time-frame. Any changes to the functionality, including micro-improvements, may incur additional costs accordingly. Please ensure and clarify our understanding in a face-to-face meeting.
• By accepting a quote, you agree to and accept the terms and conditions of 360Techno. Acceptance can be verbal, by email, payment of Initiation, or signing a quote.
• Clients to ensure that we have included all requirements in the quotes/proposals/estimates and that we fully understand their requirements. Clients must provide us with clear guidelines along with the flow or specific details they may require. When such details are not provided, we will proceed with our understanding of the requirements and quote accordingly. At a later stage, if a discrepancy arises, it may lead to additional costs to accommodate the changes. Thus, it is essential that you clarify every aspect of your website development and ensure that you have been quoted on the right requirements.
• Any complexity related to specific tasks must be advised in advance and included in the proposal for costing purposes. We operate in good faith and rely on our clients to disclose the full picture at the time of quotation. Any discrepancy arising due to unclear requirements will not be borne by 360Techno.
• There are limited man-hours allocated to each task, including Project Management and Digital Strategist/Business Analyst. Minor changes may be included within the allocated hours. This will be analyzed on a case-by-case basis.
• 360Techno will make every effort to complete the project/changes in the given timeframe. Reasonable delays are accepted if functionalities are redefined or modified.
• Any delays at the client’s end may delay the project and proposed timeframes and may incur additional costs.
• Any bugs (programming errors) reported during or just after the development do not attract additional charges.
• Any re-work on an already completed task will attract additional charges. Any changes in the design after the design approval will incur additional charges.
• Any modifications requested during the development or after the Go-Live approval will incur additional charges. All additional work, over and above the estimates, is charged separately. Under no circumstances will 360Techno be liable for any delays caused by changes in the project brief.
• Website/application content and all related materials need to be provided to us within the first two weeks of starting the project. Any delays thereafter may delay the project and may incur additional charges if it goes beyond a reasonable timeframe.
• Our websites/applications are generally tested on PCs and include near recent versions of the following browsers: IE, Firefox, Chrome & Safari. If you require testing to be done on any other browser, please let us know in advance.
• Responsive/multi-device compatible web pages are tested on iPhone and iPads. If you require testing to be done on any other device, please discuss it in advance.
• If your website/application is not hosted on a 360Techno server, any additional man-hours that may be required due to any server or network-related issues are not covered in our quotes and may be charged separately.
• Please note that at any stage during the project, stalling of the project for over two calendar months will incur $99/week administration costs. Furthermore, it may increase the previously approved estimates. If you require the project to be put on hold, please advise us in writing in advance. To put the project on hold without incurring additional charges, we will need the account to be up to date based on the work done. Further details can be discussed if such a situation arises.
• 360Techno software codes (not including open-source software) are copyrights of 360Techno. The codes can be handed over at an additional cost for use once all previous invoices are settled, on the condition that the codes are used only for use or modification for re-use for further development for the specified client or subsequent owners of that legal entity. Under no circumstance will the codes be allowed to be used for re-selling or duplication purposes.
• 360Techno CMS is a proprietary CMS of 360Techno. 360Techno owns copyrights of all codes written for any client, unless arrangements are made prior to the start of the project. 360Techno warrants a license to use any custom-built software for the client, for their use only. This license is granted while paying for the hosting. 360Techno CMS cannot be transferred to any external host; this includes any access to the software codes.
• The website or software application will be designed to be deployed on the web, via using a commercial-grade web-server or a similar setup. Based on your website traffic, the website may not perform if deployed on a generic office network environment.
• Depending upon the functionalities required, there may be 3rd party components such as Third-Party Payment Gateways or SSL certificates involved in building a website/application. Although 360Techno does its best in recognizing the suitability of any such component, any unforeseen limitations of 3rd party components are beyond our control. Any third-party component purchase costs (such as SSL, Payment gateway, Google Adwords, Plug-in licenses , Themes etc.) are not included in our quotes.
• 360Techno takes no responsibility for any open-source products such as WordPress, Open Source carts, Joomla, etc. It is the client’s responsibility to update all components and third-party software. We suggest you take regular backups to avoid any disruptions.
• 360Techno offers packages in coordination with third-party providers. Changes to the third-party provider’s rules and policies may ultimately affect the services we provide or the terms and conditions herein.
• The client must recognize that at times there may be unforeseen circumstances that will delay the development process, particularly with reference to the integration of third-party software. We will try our best to complete the project as agreed in the proposal. As long as it is within a reasonable period, the client agrees not to penalize us for any genuine delay, when every effort to keep the project on the proposed schedule is taken.
• Domain registration/renewal, etc. charges are not included as a part of any project/proposal unless mentioned otherwise. If required, a quote for which will be submitted separately and approved by the client.
• Hosting charges are not included in the quotations unless mentioned otherwise. 360Techno can organize an appropriate hosting solution if required, a quote for which will be submitted separately and approved by the client. Where clients decide to organize their own hosting, we should be consulted before finalizing the type of hosting and database, as it should meet the requirements of the technology used for the development. Please note that we’ll require full access with hosting support for testing and deploying the application. 360Techno will not be liable for any delays or errors caused by the direct or indirect actions of the hosting company.
• 360Techno generally builds and tests the websites/applications on our own servers or hosted domains. 360Techno cannot give access to their test servers and test websites to the clients or any third party. The website/application can be transferred-off to a nominated 3rd party server upon full payment of all invoices and dues.
• All communications/correspondences are generally done via emails. It is client’s responsibility to keep us updated with their relevant email addresses.
For general website design & development projects at 360Techno, we follow the following steps:
Initiation: After quote acceptance, initiation payment is processed, and a Scoping Workshop may be conducted to discuss requirements.
Design Mock-up: Within 5 to 10 working days, we present a design mock-up using your brand details for your review.
Design Review: You can suggest up to 3 to 5 design modifications within the allocated hours.
HTML Development: Once the design is approved, HTML development begins. We need 3 to 5 banner text/images for rotation.
CMS Setup: If CMS is included, we set up your website on the selected Content Management System. Provide all content before development.
Content Transfer: We transfer as much content as possible. Your staff can handle the remaining via the CMS with our guidance.
Review & Testing: We hand over the site for your review, testing, and content updates.
Go-Live Approval: Provide a Go-Live date for the website to be made live.
Website Live: After Go-Live approval, the website can be live within 3 to 5 working days, subject to full payment.
Project Timeline: Projects under $5000 are typically completed in 8 to 12 weeks. Delays may incur additional costs.
Efficiency: Provide all necessary details at the project start to optimize time and avoid extra costs.
Communication: We keep you updated via emails/phone calls and welcome your project status inquiries.
Responsibilities: After website/application goes live, you are responsible for regular backups and updates.
At 360Techno, we are flexible, adaptable, and approach all requests with a ‘can do’ attitude. Feel free to discuss any changes or questions. We look forward to collaborating with you on your project!
Domain
All domain registrations and renewals are to be paid in advance.
Expiration of a domain can result in service disruption and loss of the domain.
360Techno will not be responsible if a domain expires due to non-payment / late payment of the charges. All payments must be made by seven working days before the expiry date.
It is the client’s responsibility to renew their domain names with us.
All invoices and dues must be paid in full before we release the requested domain name.
360Techno has the domains in a common pool account and therefore cannot give access to its domain control panel.
360Techno offers packages in coordination with third-party providers. Changes to the third-party provider’s rules and policies may ultimately affect the services we provide or the terms and conditions herein.
Hosting
Hosting is an annual charge that must be paid in advance for the whole year unless the client is under one of our Maintenance packages.
The client is responsible for renewing the hosting before the expiry date. Failure to do so may result in the loss of files, data, emails, backups, etc. Unpaid hostings are disabled or deleted from the server.
Renewals must be paid seven working days before the expiry date. 360Techno will not be responsible for issues related to delayed payment.
Our hosting services are on shared and non-shared servers hosted via third-party providers. We make best efforts to protect our systems from hackers, viruses, intruders, and other problems, but we are not liable for any disruption of services in such situations.
The client is solely responsible for the content stored on the hosting service and the activity of any scripts or email services. The client must maintain the security of account passwords and ensure scripts are free from malicious content.
In case of a malware attack, 360Techno reserves the right to delete files on the hosting service without prior notice.
Cancellation/Termination:
Hosting cancellation requests must be sent in writing or by email one month prior to the expiry date. Once renewed, hosting cannot be cancelled and must be paid for the full year.
If hosting is not paid and renewed before the expiry date, we reserve the right to disable all associated services, and additional charges will apply to re-enable the hosting. 360Techno will not be responsible for any loss of data, files, emails, backups, restoration costs, etc.
If hosting is cancelled or disabled, all files, emails, databases, and backups will be deleted from the server without prior notification to the client.
Once all invoices are paid, the client can request files subject to the following:
– 360Techno’s CMS is proprietary and cannot be transferred to any external host.
– FTP and Control panel access is not provided for websites using 360Techno’s CMS.
Emails:
All emails must be downloaded to the client’s computer periodically. Email boxes must be kept within their quota limits. Periodical maintenance may result in the deletion of emails older than 6 months.
Clients must not use email hosting for inappropriate content or spamming, as immediate action will be taken, and files and data may be deleted without prior notice.
360Techno offers packages in coordination with third-party providers. Changes to the third-party provider’s rules and policies may affect the services we provide or the terms and conditions herein.
Hosting services are on shared and non-shared servers hosted via third-party providers. While we make best efforts to protect our systems, we will not be held liable for any disruption of services due to online or offline problems.
All content of this website is the property of 360Techno unless otherwise specified. 360Techno reserves the right to change the content or policies without any prior notice.
The project-related copyrights can be transferred to the client at an additional cost, after the full payment of the project and upon signing the Certificate of Acceptance. 360Techno reserves the right to refuse the transfer of ownership if irregular circumstances arise.
Copyrights handed over to the client do not include rights to re-use the code for another website or re-sell the programming codes for any commercial or non-commercial purposes. In the case of business restructuring or ownership change, ownership of the website may be transferred from one owner to another. New owners are not allowed to re-sell or re-use for any commercial or non-commercial purpose.
In the event of a Webmaster change, site owners are not allowed to display credits to the new website, unless the website functionality and appearance are changed by over 50% of our original work.
In the event of a dispute, 360Techno reserves the right to charge the client in full for the work done as well as for the resources spent in managing the dispute. In such an event, 360Techno reserves the right to charge the client without honoring any discounts that were previously honored in good faith. Under no circumstances will 360Techno be liable for any damages arising from misrepresentation or misinformation.
360Techno reserves the right to refuse service to any client if they are not aligned with our business operating principles and policies.
360Techno provides its services as is, without any guarantees on security or other issues leading to the loss of data, sale, or reputation. We ensure to the best of our ability that our systems and servers are protected from hackers, viruses, intruders, and other online and offline problems; however, we will not be held liable for any disruption of services if such a situation arises.
The relationship of 360Techno with its suppliers, partners, and sub-contractors is of an independent nature. None of the parties have any power, right, or authority to interfere or bind the other or assume or create any obligation or responsibility, whether expressed or implied, on behalf of the other or in the other’s name.
The client will indemnify and hold 360Techno, its licensors, content providers, service providers, employees, agents, officers, directors, contractors, and sub-contractors (the “Indemnified Parties”) harmless from your breach of any of these Terms And Conditions or any other terms, conditions, policies, or procedures herein, including, without limitation, any use of content other than as expressly authorized in these Terms And Conditions. The client agrees that the indemnified parties will have no liability in connection with any such breach or unauthorized use, and the client agrees to indemnify and hold harmless the Indemnified Parties from any and all resulting loss, damages, judgments, awards, costs, expenses, and attorneys’ fees in connection therewith. The client will also indemnify and hold the Indemnified Parties harmless from and against any claims brought by third parties arising out of the client’s use of the information obtained from 360Techno.
360Techno will not be liable for any breach of the agreement caused by a matter beyond its reasonable control, including but not limited to Act of God, fire, lightning, explosion, war, disorder, flood, earthquake, industrial disputes (whether or not involving their employees), extremely severe weather, or acts of local or central government or other competent authorities.
- Hosting and Domain is Not Included In This Package.
- This Price only includes the features That are mentioned above list. if You need more features it cost additionally.
- This price doesn’t includes any SEO and Marketing Features And Strategies.
- Project Will be Start after the initial advance payment.
- Maintenance is Not includes in This Price.
- We only Provide our Service of technical issue till 30 Days After Project Handover to the client.
- We only Upload some products (up to 10) for demo.
- Project will be Handover to Client after Full Payment.
- Project duration is around 3-4 week if all required data from client will on time.
Also Read This Terms
360Tehno Note:-
All content of 360techno.in is a property of 360Tehno and their business partner unless otherwise specified. 360Tehno reserves the right to change the content or policies without any prior notice.
